- Ask about any monthly specials
Effective from: 1st January 2026
These Terms and Conditions govern your use of the Grill Plus website, services, and all related transactions. By accessing our website, requesting a quote, scheduling a consultation, purchasing products, or hiring us for services, you agree to be legally bound by these Terms. If you do not agree, you must not use our website or services.
Grill Plus provides custom outdoor kitchens, built-in grills, stone and brick finishes, and related outdoor kitchen accessories. These Terms apply to all customers, site visitors, and users located in Mesquite, Nevada, and surrounding service areas.
We reserve the right to update or modify these Terms at any time without prior notice. Continued use of our services after changes are posted means you accept those changes.
Grill Plus specializes in the design, sale, and installation of custom outdoor kitchens and related products. Our services include, but are not limited to:
All services are provided based on the specific requirements of each customer. The final scope of work is outlined in a written estimate, agreement, or invoice.
We do not provide electrical, plumbing, or gas permitting unless explicitly stated in writing. Where outside licensed services are required, coordination may be the homeowner’s responsibility unless otherwise agreed.
All estimates provided by Grill Plus are non-binding until confirmed in writing through a signed agreement. Pricing is based on materials, labor, design complexity, site access, and current market conditions.
Prices may change due to:
Additional work requested beyond the original scope will be quoted separately and must be approved before proceeding.
Payment terms will be clearly outlined in your service agreement or invoice. Typical payment structures may include:
All payments must be made in full and on time. Late payments may result in work stoppage, delays, or added fees.
We use secure payment processors to protect your financial information. Grill Plus does not store full credit card numbers on its servers.
Failure to make payments as agreed gives Grill Plus the right to suspend work, remove materials if legally permitted, and pursue legal collection remedies.
Project timelines are estimates only. While we make every effort to meet scheduled completion dates, delays may occur due to:
Grill Plus is not liable for delays beyond reasonable control. Any timeline adjustments will be communicated promptly.
The customer agrees to:
Failure to meet these responsibilities may cause delays or additional costs.
All products are intended for proper outdoor use only. Customers are responsible for:
Grill Plus is not responsible for injuries, damage, or losses caused by misuse, neglect, or improper operation.
Grill Plus provides a workmanship warranty as outlined in your service agreement. Manufacturer warranties apply separately to grills, accessories, and appliances.
Workmanship warranty does not cover:
Warranty claims must be submitted in writing within the warranty period.
All content on the Grill Plus website, including text, images, logos, graphics, and designs, is owned by Grill Plus and protected under United States intellectual property laws.
You may not copy, reproduce, distribute, or use our materials without written permission.
You agree not to:
We reserve the right to terminate access to users who violate these rules.
To the fullest extent allowed by law, Grill Plus shall not be liable for:
Our total liability will never exceed the amount paid for the specific service involved.
You agree to indemnify and hold harmless Grill Plus, its owners, employees, and contractors from any claims, damages, or losses resulting from your misuse of products, violation of these Terms, or negligence.
Projects may be canceled by the customer only in writing. Deposits are non-refundable once materials are ordered. If cancellation occurs after work begins, the customer is responsible for all completed labor and materials used.
Grill Plus reserves the right to terminate services if:
Some products may be sourced from third-party manufacturers. Grill Plus is not responsible for manufacturer delays, defects, or warranty policies. Manufacturer warranties apply directly to those products.
Your privacy is important to us. Personal information collected through our website is used only for communication, service delivery, and billing purposes. We do not sell or share customer data except where required by law.
These Terms are governed by the laws of the State of Nevada and applicable United States federal laws. Any disputes shall be resolved exclusively in the courts located in Clark County, Nevada.
Grill Plus shall not be held responsible for failure to perform due to events beyond reasonable control, including natural disasters, strikes, supplier shutdowns, government restrictions, or unforeseen emergencies.
If any section of these Terms is found to be unenforceable, the remaining sections will continue in full legal force.
These Terms, along with your service agreement or invoice, represent the full agreement between you and Grill Plus. No verbal statements override written agreements.
If you have questions about these Terms and Conditions, you may contact us directly through our website or customer service channels.